Terms & Conditions

Last Updated: August 14, 2026

Welcome to the website of Contractors Hub LTD (“Contractors Hub,” “we,” “us,” or “our”). These Terms & Conditions govern your access to and use of our website and the information and services made available through it.

By accessing or using this website, you acknowledge that you have read, understood, and agree to these Terms & Conditions. If you do not agree with these terms, please do not use this website.

Contractors Hub LTD is a commercial construction company providing construction and related services for commercial clients and projects. Our services may include commercial construction, renovations, project management, construction coordination, and other services described on our website or in a project-specific agreement. Information regarding our services, experience, projects, team, and capabilities is provided for general informational purposes.

You may use this website for lawful purposes and to learn about Contractors Hub LTD, our services, and our commercial construction projects.

You agree not to:

• Use the website for unlawful or fraudulent purposes;
• Attempt to gain unauthorized access to the website or its systems;
• Interfere with the security or operation of the website;
• Copy or reproduce website content without permission;
• Use our content, branding, photographs, or materials for commercial purposes without our written consent; or
• Submit false, misleading, or unauthorized information through our website.

We reserve the right to restrict or terminate access to the website where we believe these Terms & Conditions have been violated.

We make reasonable efforts to ensure that information displayed on our website is accurate and current.

However, information may change from time to time without notice. Project descriptions, photographs, statistics, service descriptions, timelines, and other information are provided for general informational purposes and should not be considered a guarantee of future results or project outcomes.

Information displayed on the website does not create a contractual relationship between Contractors Hub LTD and a website visitor.

A binding agreement for construction services will only arise through a written agreement, contract, proposal, quotation, or other documentation accepted by Contractors Hub LTD and the client.

Any quote, estimate, budget, pricing information, or project information provided through our website, email, telephone, or other communication is subject to the applicable terms of the project. Unless expressly stated otherwise in writing, estimates are not guarantees of final project costs.

The final cost of a project may be affected by factors including:

• Changes to the project scope;
• Client-requested changes;
• Material price changes;
• Labour costs;
• Permit or inspection requirements;
• Unforeseen site conditions;
• Structural or existing-condition issues;
• Delays or changes caused by third parties;
• Additional work requested or required; and
• Other circumstances affecting the project.

Any applicable quote or proposal will identify the scope, pricing, assumptions, exclusions, and other conditions applicable to the project.

Construction services provided by Contractors Hub LTD are governed by the applicable written contract, proposal, quotation, purchase order, or other project agreement.

The project agreement may establish:

• Scope of work;
• Project price;
• Payment schedule;
• Construction schedule;
• Materials and specifications;
• Responsibilities of the client and Contractors Hub LTD;
• Change-order procedures;
• Warranty provisions;
• Completion requirements;
• Insurance requirements;
• Termination provisions; and
• Other project-specific terms.

If there is a conflict between these website Terms & Conditions and a signed project agreement, the applicable project agreement will govern the construction project.

Construction projects may change during the course of the work.

A client may request changes to the original scope of work. Changes may affect the project price, materials, schedule, labour requirements, or completion date.

Where applicable, additional work or changes will be documented through a written change order or other written approval.

Contractors Hub LTD is not responsible for delays or additional costs resulting from client-requested changes or delayed client decisions, approvals, selections, or instructions.

Construction and renovation projects may involve conditions that cannot reasonably be identified before work begins.

These may include concealed structural issues, existing damage, hazardous materials, unsuitable soil, hidden utilities, outdated systems, moisture, mould, or other conditions that were not reasonably apparent during initial assessments.

If unforeseen conditions are discovered, Contractors Hub LTD will communicate the issue to the client where reasonably possible.

Additional work required to address unforeseen conditions may result in additional costs and/or changes to the project schedule, subject to the applicable project agreement and applicable law.

We make reasonable efforts to complete projects according to the agreed schedule. However, construction schedules can be affected by circumstances outside our reasonable control.

These may include:

• Severe weather;
• Material shortages or supplier delays;
• Labour shortages;
• Permit or inspection delays;
• Utility interruptions;
• Unforeseen site conditions;
• Client-requested changes;
• Delayed approvals or decisions;
• Actions or delays of subcontractors or other third parties;
• Government requirements;
• Emergencies;
• Acts of nature; and
• Other circumstances beyond our reasonable control.
• 
  

Where reasonably possible, Contractors Hub LTD will communicate significant schedule changes to the client.

Clients are expected to cooperate with Contractors Hub LTD throughout the project.

Depending on the project, client responsibilities may include:

• Providing reasonable access to the property;
• Providing accurate project information;
• Providing timely approvals and decisions;
• Making required selections;
• Providing access to relevant documents and information;
• Keeping required areas accessible;
• Making payments when due; and
• Complying with responsibilities established in the applicable project agreement.
• 
  

Delays resulting from failure to meet these responsibilities may affect project costs and timelines.

Construction projects may require permits, inspections, approvals, drawings, engineering, or other regulatory requirements.

Responsibility for obtaining specific permits or approvals will be determined by the applicable project agreement and the requirements of the relevant authorities.

Clients are responsible for providing accurate information and cooperating with Contractors Hub LTD and applicable authorities where required.

Contractors Hub LTD may engage qualified subcontractors, tradespeople, suppliers, consultants, or other professionals as necessary to complete a project.

The use of subcontractors and suppliers does not relieve Contractors Hub LTD of its obligations under the applicable project agreement.

Payment terms are established in the applicable contract, proposal, quotation, invoice, or other project documentation. Clients are responsible for making payments according to the agreed payment schedule. Failure to make payments when due may result in suspension of work, delays, additional costs where permitted by the applicable agreement and law, or other remedies available to Contractors Hub LTD. Any payment-related rights and obligations will be subject to the applicable contract and applicable Ontario law.

Any warranties provided by Contractors Hub LTD will be governed by the applicable project agreement.

Certain materials, products, equipment, or systems may also be subject to manufacturer or supplier warranties.

Unless expressly provided in writing, information on this website does not create or extend any warranty.

Nothing in these Terms & Conditions is intended to exclude or limit any warranty, protection, or right that cannot legally be excluded or limited under applicable law.

Contractors Hub LTD is committed to maintaining a safe working environment and following applicable workplace health and safety requirements. Construction sites may contain hazards and restricted areas.

Website visitors, clients, contractors, and other persons must not enter restricted construction areas without appropriate authorization.

Visitors must follow all applicable site safety instructions and requirements.

Contractors Hub LTD may display photographs, videos, descriptions, or other information relating to completed or ongoing projects for portfolio, marketing, and promotional purposes, subject to applicable rights and permissions.

We will make reasonable efforts to respect client confidentiality and any contractual restrictions regarding project photography or publication.

All content on this website, including but not limited to:

• Company name and branding;
• Logos;
• Text;
• Photographs;
• Graphics;
• Videos;
• Designs;
• Project descriptions;
• Marketing materials; and
• Other website content

is owned by or licensed to Contractors Hub LTD unless otherwise stated.

You may not reproduce, distribute, modify, publish, sell, or commercially use our website content without our prior written permission.

Our website may contain links to third-party websites, suppliers, organizations, or other resources.

These links are provided for convenience only.

Contractors Hub LTD does not control and is not responsible for the content, availability, security, accuracy, or practices of third-party websites.

Your use of third-party websites is subject to their respective terms and privacy policies.

We make reasonable efforts to maintain the availability and security of our website.

However, we do not guarantee that the website will always be available, uninterrupted, secure, or free from errors or technical issues.

We may modify, suspend, or discontinue any portion of the website without notice.

To the fullest extent permitted by applicable law, Contractors Hub LTD will not be responsible for losses or damages arising solely from a person's use of, or inability to use, this website or from reliance on general information published on the website.

This limitation does not apply to liability that cannot legally be excluded or limited under applicable law.

Any liability relating to construction services, projects, workmanship, contracts, or other services provided by Contractors Hub LTD will be governed by the applicable project agreement and applicable law.

When you contact Contractors Hub LTD through our website, you may provide personal information such as your name, telephone number, email address, company information, or project information.

We may use this information to respond to inquiries, communicate with clients and prospective clients, provide requested services, and conduct legitimate business activities.

Personal information will be handled in accordance with our applicable privacy practices and privacy policy.

Information provided through this website is general information only.

Nothing on this website should be interpreted as legal, financial, engineering, architectural, accounting, or other professional advice.

Where professional advice is required, you should consult the appropriate qualified professional.

Testimonials, project descriptions, photographs, statistics, and other examples presented on our website are provided for informational and promotional purposes. Past project results and client experiences do not guarantee that a future project will have the same outcome.

Each construction project is unique and may involve different site conditions, requirements, budgets, schedules, and circumstances.

These Terms & Conditions are governed by the laws of the Province of Ontario and the applicable laws of Canada.

Any dispute arising out of or relating to these Terms & Conditions or the use of this website will be governed by the applicable laws of Ontario and, where applicable, the laws of Canada. Any such dispute will be subject to the jurisdiction of the courts of Ontario, unless otherwise required by law or agreed to in a separate written agreement.

Contractors Hub LTD reserves the right to modify or update these Terms & Conditions at any time.

Updated Terms & Conditions will be posted on this website with a revised “Last Updated” date.

Your continued use of the website following the posting of changes constitutes acceptance of the updated Terms & Conditions.

If any provision of these Terms & Conditions is determined to be invalid, unlawful, or unenforceable, the remaining provisions will continue to apply to the fullest extent permitted by law.

If you have questions about these Terms & Conditions or Contractors Hub LTD's services, please contact us:

Contractors Hub LTD

Ontario, Canada

Email: info@contractorhubs.com
Phone:  +1 647-671-5550
Website:  Contractors Hubs Ltd